Terms and conditions
Introduction
These Terms and Conditions (“Terms”) govern your use of the Award Kitchens website and our services. By accessing this website or engaging with our services, you agree to be bound by these Terms. If you do not agree, please refrain from using our website or services.
About award kitchens
Award Kitchens provides custom kitchen, joinery, and cabinetry services including, but not limited to, kitchen cabinets, built-in wardrobes, bathroom vanities, display cabinets, and outdoor kitchens.
Use of website
You agree to use this website for lawful purposes only. You must not use the website in any way that may cause damage, impair its availability, or interfere with other users’ access. We reserve the right to update, modify, or remove website content at any time without notice.
Enquiries, quotes, and estimates
Any information, estimates, or quotations provided through the website, email, or phone are indicative only unless confirmed in writing. Final pricing, scope of work, timelines, and specifications will be agreed upon in a formal written agreement before work commences.
Services and scope of work
All services are subject to availability and agreement. The scope of work, materials, timelines, and payment terms will be clearly outlined in a project agreement provided prior to commencement. Any variations to the agreed scope may result in additional costs or changes to timelines.
Payments and fees
Payment terms will be outlined in your project agreement. Deposits may be required prior to manufacturing or installation. Failure to make payments in accordance with agreed terms may result in delays or suspension of work. All prices are in Australian Dollars unless otherwise stated.
Intellectual property
All content on this website, including text, images, logos, designs, and layouts, is the property of Award Kitchens unless otherwise stated. You may not reproduce, distribute, or use any content without prior written permission.
Warranties and liability
We take reasonable care to ensure our services are delivered to a high standard. Any warranties applicable to workmanship or materials will be outlined in your project agreement. To the extent permitted by law, Award Kitchens is not liable for indirect or consequential loss arising from the use of our website or services.
Nothing in these Terms excludes rights provided under Australian Consumer Law.
Project delays and force majeure
We are not responsible for delays caused by circumstances beyond our control, including but not limited to supplier delays, weather conditions, access issues, or acts of nature.
Third-party links
Our website may contain links to third-party websites for convenience. We do not control or endorse these sites and are not responsible for their content or practices.
Privacy
Your use of this website is also governed by our Privacy Policy, which outlines how personal information is collected and handled.
Changes to these terms
We reserve the right to update or amend these Terms at any time. Any changes will be effective once published on this page.
Governing law
These Terms are governed by the laws of New South Wales, Australia. Any disputes arising in connection with these Terms will be subject to the jurisdiction of the courts of New South Wales.
Contact us
If you have any questions regarding these Terms and Conditions, please contact us: